SERVICE CONTRACT.

SERVICE CONTRACT.

This Contract herein is made this _______ day of ______________ 20__ between SUPERIOR SEAMLESS GUTTERS, of 1112 S Range Ave 110 STE 118 Denham Springs LA 70726, herein referred to as the “Contractor” and ______________________________ herein referred to as the “Client”. Herein all together referred to as “the parties”.

1. Projects.

The parties herein agree that the Contractor will provide the following services; 

1. ………………………………….
2. ………………………………….
3. …………………………………

2. Payments.

In consideration of the labor, material, and repair, if any, by the Contractor, the Client agrees to pay the Contractor as follows; –

Contract Price, including tax: ……………………………..…….

Down Payment: ……………………………………………..……

Unpaid Balance: …………………………………………………..

Approximate Start & Completion Date: ……………………….

Payment terms: …………………………………………………..

Any unpaid balance of each installment shall be paid when the works are completed. 

3. Expenses.

The Client agrees to pay for any expenses incurred by the Contractor for the services under this Agreement.

4. Indemnity.

The Client agrees to hold harmless and indemnify the Contractor from any claim or liabilities that may arise from the performance of this Contract. 

5. Dispute/Conflict Resolution.

If there arises any conflict or dispute during the performance of this Contract, the same shall be negotiated between the parties amicable. If the same fails, the disagreement or dispute shall be settled through mediation with the help of an independent mediator and the party’s goodwill.

6. Governing Law.

This Contract shall be governed and construed in accordance with the laws of the State of Louisiana.

7. Termination.

Either party to this Contract can terminate the performance by issuing 14 days’ written notice, stating the reasons for termination, which include but are not limited to; –

1. Late Payments.
2. Lack of communication from the Client.

8. Force Majeure.

Neither of the parties to this Contract shall be considered to be in breach to the extent that the performance of their respective obligations is prevented by an event of force majeure, which is an act beyond the control of the parties, including but not limited to Acts of God, civil war, riot, strikes or terrorism.

9. Modification.

Either party to this Contract may modify the provisions and terms herein by the same modification being in writing and signed by both parties.

10. Waiver.

No waiver by either party of any default shall be deemed a waiver of prior or subsequent default of the same of other provisions of this Contract.

11. Severability.

Suppose any term, clause, or provision hereof is held invalid or unenforceable by a court of competent jurisdiction. In that case, such invalidity shall not affect the validity or operation of any other term, clause, or provision, and such invalid term, clause, or provision shall be deemed to be severed from the Contract.

12. Assignment.

Neither party to this Contract may assign or transfer its rights and obligations without the prior written consent of the other party. 

13. Entire Agreement.

This is the entire Agreement between the parties, and it supersedes any prior negotiations, promises, or contracts, either written or Oral.

IN WITNESS WHEREOF, the parties have executed this Agreement as of the date hereinbelow; –