CONSTRUCTION SERVICE AGREEMENT
This Construction Service Agreement, herein referred to the "Agreement," made this
_______ day of ______________ 20__ between MKYLE AND COMPANY, herein
referred to as “The Contractor” and _______________________ herein referred to as
“The Client” for services in connection with Construction of the following described
project: ____________________________________.
WHEREAS the Contractor desires to provide Construction Services to the Client, and the
Client desires to obtain the said construction services from the Contractor.
THEREFORE, in consideration of the mutual promises set forth below, the Contractor
and the Client shall agree to the terms and conditions herein contained in this Contract
and enumerated as follows:
1. Description of Service.
The Contractor agrees to perform in a good and workmanlike manner and shall provide
all services, materials, and labor listed in the attachment.
2. Documents.
Any related documents, such as designs, drawings, or work descriptions related to the
service to be provided, shall be supplied by the Client unless the Client explicitly instructs
the Contractor to obtain the same on their behalf.
3. Payment Terms.
In consideration of the performance of the Agreement, the Client agrees to pay to the
Contractor in current funds as compensation for the services as follows:
……………………….
……………………….
For delays in the Project, which are not the Contractor’s responsibility, there will be an
equitable adjustment in the fee to compensate the Contractor for his increased expenses.
4. Changes/Modifications.
Any party herein can request any changes to the terms in the agreement and/or the
scope of work or service being performed, as well as any cost associated with change
requests upon a written request (which will not be unreasonably withheld), and parties will
prepare an addendum to this contract.
5. Subcontracts.
A Subcontractor is a person or entity with a direct contract with the Contractor to perform
any Work in connection with the Project. The term Subcontractor does not include any
separate contractor employed by the Owner or the independent contractors’
subcontractors.
All portions of the Work that the Contractor does not perform with his forces shall be
performed under subcontract.
No contractual relationship shall exist between the Owner and any Subcontractor. The
Contractor shall be responsible for the Subcontractors’ management in their work
performance.
6. Commencement and Completion of Work.
The Contractor will not begin work or order any materials before the third (3) day
following the signing of this Agreement, unless otherwise specified here in writing. The
Contractor will begin work on, or about ________________________. Barring any delay
caused by circumstances beyond the Contractor’s control, the work shall be completed by
________________________.
7. Construction-Related Permits.
The following construction-related permits will be necessary to complete the scope of the
work included in this Agreement:
______________________________
______________________________
The Contractor, in accordance with current state and federal laws, shall be required to
apply for and obtain all construction-related permits. The contractor shall not be deemed
responsible for delays in the work described in this Agreement caused by regulatory,
permit granting, inspection agencies, authorities, or individuals.
8. Dispute/Conflict Resolution.
The Contractor and the Client hereby mutually agree to have mutual negotiations if there
arises a dispute concerning this contract. If the negotiations fail, parties may resolve the
issue through Arbitration. The decision and award of the arbitrator shall be final. The
costs of such proceedings shall be borne equally by both parties.
9. Indemnification.
The Client agrees to indemnify and hold harmless the Contractor and its employees from
and against all liability, claims, demands, and expenses, including court costs and
attorney fees, on account of any injury, loss, or damage, which may arise out of or are in
any manner connected with the work to be performed under this Contract, if any such
injury, loss or damage is caused in whole or in part by or is claimed to be caused in whole
or in part by, the negligent acts, errors, or omissions of the Contractor, any Subcontractor
of the Contractor, or any officer, employee, or agent of the Contractor.
The obligations of this Section shall not apply to damages which the Contractor shall
become liable by final judgment to pay to a third party as the result of the negligent act,
error, or omission of the Contractor.
10. Governing Law.
This Agreement shall be governed by and construed in accordance with the laws of ____.
11. Severability.
Suppose any term, clause, or provision hereof is held invalid or unenforceable by a court
of competent jurisdiction. In that case, such invalidity shall not affect the validity or
operation of any other term, clause, or provision, and such invalid term, clause, or
provision shall be deemed severed from the Agreement.
IN WITNESS WHEREOF, each of the Parties has executed this Contract, as of the day
and year set forth above.
Signed by the duly Authorized
Representative of the CONTRACTOR;
Signed by the duly Authorized
Representative of the CLIENT;
Signature: …………………………………… Signature:
……………………………………
Name: ………………………………………
..
Name: ………………………………………
Designation: ………………………………… Designation:
…………………………………
Date: ………………………………………… Date:
…………………………………………
Telephone:
……………………………………
Telephone:
……………………………………
Email Address: ……………………………… Email Address:
………………………………
SCOPE OF WORK:
DEMOLITION
GRADING PER PLAN
o CIVIL ENGINEERING AND ANY RELATED VERIFICATIONS AND SITE
INSPECTION COSTS/CHARGES WILL BE THE OWNER’S
RESPONSIBILITY
UNDERGROUND PLUMBING PER PLAN
PLUMBING
o RHEEM (2) SYSTEM TANKLESS WATERHEATER INCLUDED.
MAIN: 3-5 BATHROOM TANKLESS SYSTEM
ADU: 1-2 BATHROOM TANKLESS SYSTEM
o PLEASE NOTE* DUNN & EDWARD’S COLORS AND TYPE OF
SHEENS WILL BE
OWNER CHOICE BUT LIMITED TO 2 COLORS FOR THE ENTIRE INTERIOR
RESIDENT
FRAMING PER PLAN
o STRUCTURAL ALTERATION/CHANGES CAN CAUSE DELAYS IN
PROJECT TIMING AND FINISH
o CHANGES OUTSIDE PER PLAN FRAMING WILL BE CHARGED
ACCORDINGLY PER OWNER AND MYKLE FOR MATERIALS AND
LABOR
o HEIGHT/FRAMING/ANCHOR BOLTS/STRAPS ETC & SITE
INSPECTION FROM STRUCTURAL ENGINEER WILL BE THE
OWNER’S RESPONSIBILITY
o *PLEASE NOTE* CERTAIN PLAN/STRUCTURE CALLS OUT
TRUSS ROFF SYSTEM, WHICH CAN CAUSE DELAYS
STRAIGHT EDGE FRAMING
WINDOWS/DOORS PER PLAN
ELECTRICAL PER PLAN
o 6” CAN BOX WITH LUMEN OF CHOICE
o EXTERIOR LIGHTING TO BE STANDARD PER PLAN
o BATHROOM LIGHTING TO BE STANDARD PER PLAN
o HOME AUTOMATION IS NOT INCLUDED
o SECURITY CAMERA PREWIRING IS NOT INCLUDED. IF INTERESTED,
$50 PER LINE PULLED VIA CAT6.
o STANDARD BATHROOM FANS ARE INCLUDED. UPGRADES FOR
ADDITIONAL COST.
o MECHANICAL PER PLAN
o SLIMLINE A/C OR SHEER UPGRADE WILL BE CONSIDERED AT THE
TIME OF QUOTE
o INSULATION PER PLAN
o FULL INTERIOR INSULATION WILL BE AN ADDITIONAL CHARGE
o DRYWALL TO BE 5/8 TEXTURED
o LEVEL 4/5 SMOOTH FINISH WILL BE AN ADDITIONAL CHARGE
o BATHROOM VAPOR BARRIER & WATERPROOFING CHANDELIER
WILL BE OWNER’S
o EXTERIOR LIGHTING TO BE STANDARD PER PLAN
o BATHROOM LIGHTING TO BE STANDARD PER PLAN
o HOME AUTOMATION IS NOT INCLUDED
o SECURITY CAMERA PREWIRING IS NOT INCLUDED. IF
INTERESTED, $50 PER LINE PULLED VIA CAT6
o STANDARD BATHROOM FANS ARE INCLUDED. UPGRADES
FOR ADDITIONAL COST.
MECHANICAL PER PLAN
o SLIMLINE A/C OR SHEER UPGRADE WILL BE CONSIDERED AT
THE TIME OF QUOTE
INSULATION PER PLAN
o FULL INTERIOR INSULATION WILL BE AN ADDITIONAL CHARGE
DRYWALL TO BE 5/8 TEXTURED
o LEVEL 4/5 SMOOTH FINISH WILL BE AN ADDITIONAL CHARGE
BATHROOM VAPOR BARRIER & WATERPROOFING TYPES
o LEVEL A WATERPROOFING – $100 PER SHOWER
o LEVEL B WATERPROOFING – INCLUDED
o FLOAT ON – $400 PER SHOWER, $750 FOR MAIN BATHROOM OR
OVERSIZED SHOWER COMPARTMENTS
o HARDIEBACKER – STANDARD FINISH INCLUDED
TILES
o STANDARD FINISH OF $2.50 SQFT
o UPGRADED TILES $3.50 – INCLUDED FOR ALL FLOORS AND
SHOWERS
o UPSTAIRS – $3 WATERPROOF FLOORING – INCLUDED
o WALLPAPERS COSTS/LABOR PER JOB/BID
o KITCHEN ALL CABINETS, BATHROOMS, AND KITCHEN AS
PLAN – SOURCED WITH 405 CABINETS & STONES
o STONE COUNTERTOPS ARE PREFAB
o APPLIANCES ARE TO BE PROVIDED BY THE OWNER
EXTERIOR
o STONES – $6.25 SQFT
o STUCCO – 20/30 SPRAY ON PER PLAN
SMOOTH STUCCO – ADDITIONAL COST
CORNINGS/EXTERIOR CROWN FOAM MOUNTINGS –
ADDITIONAL COST
ROOFING MATERIALS PER PLAN
PUBLIC WORKS
o CURB/GUTTER, SIDEWALKS, WATER METER UPGRADE,
DRAINAGE SYSTEM, AND CUSTOM LANDSCAPING WILL BE PAID
FOR BY THE OWNER
16562 GOTHARD ST UNIT G
HUNTINGTON BEACH CA,92647
(714) 510-4753
At Legal writing experts, we would be happy to assist in preparing any legal document you need. We are international lawyers and attorneys with significant experience in legal drafting, Commercial-Corporate practice and consulting. In the last few years, we have successfully undertaken similar assignments for clients from different jurisdictions. If given this opportunity, The LegalPen will be able to prepare the legal document within the shortest time possible. You can send us your quick enquiry ( here )